Disputes & Arbitration
Environment & Urban Planning
Wastewater treatment plant — Algeria
Building
Mission details
Objectives
- Analysis of the impact of changes and disruptions on the schedule
- Contribution to the rejoinder memorandum and advocacy before the Arbitral Tribunal
Stakes
- €5M of cost overruns claimed on a €11M overall contract
- End-of-project delay estimated at 49 months on an initial 18-month schedule, with 38 months attributable to the co-contractor according to our analysis.
Results
Delay of at least 5.5 months on an initial 14-month schedule; €8M plus interest.